Terms and Conditions
Welcome to Bimitry! By using our website, engaging with our services, or entering into a contractual agreement with us, you agree to the following Terms and Conditions. These terms outline the rights and obligations of both Bimitry and our clients. Please read carefully to ensure you fully understand your responsibilities and our commitments.
1. Acceptance of Terms
By accessing our website or using our services, you confirm that you agree to be legally bound by these Terms and Conditions. If you disagree with any part of these terms, you should not use our services or interact with our website. These terms apply to all users, including prospective and current clients, as well as third parties collaborating on projects. Any changes to these Terms and Conditions will be communicated clearly and made effective upon posting on our website.
2. Definitions
Bimitry
Refers to the company offering architectural, design, and project management services.
Services
Encompass all solutions provided by Bimitry, such as architectural planning, BIM (Building Information Modeling), interior design, and project execution.
Client
Refers to the individual, organization, or entity contracting Bimitry for services.
Deliverables
Are the tangible and intangible outputs, such as floor plans, 3D models, and custom fabrications, that result from our services.
These definitions are provided to ensure clarity throughout these Terms and Conditions.
3. Scope of Services
Bimitry specializes in comprehensive architectural and design solutions tailored to meet client needs. Our services include, but are not limited to:
Schematic Design (SND)
Creating initial plans that define the spatial organization, flow, and functionality of your space.
BIM and 3D Modeling
Enabling virtual visualization of your space, allowing informed decision-making before construction.
Sustainability Consultation
Designing eco-friendly and energy-efficient spaces using sustainable materials and techniques.
End-to-End Project Management
Overseeing every aspect of your project, from planning and permitting to execution and completion.
Each project’s scope, deliverables, and timelines will be explicitly outlined in a separate project-specific agreement. Bimitry is committed to maintaining the highest standards of quality and professionalism in all services provided.
4. Intellectual Property
All intellectual property, including designs, drawings, 3D models, schematics, and other materials created by Bimitry, remains the exclusive property of Bimitry unless otherwise agreed upon in writing. This includes:
Architectural and Design Concepts
Rights to architectural and design concepts developed during the project.
Proprietary BIM Processes
Ownership of proprietary BIM processes, methodologies, and tools.
Clients may use deliverables solely for their intended purpose, and unauthorized reproduction, distribution, or modification of these materials is strictly prohibited.
5. Client Responsibilities
To ensure the success of your project, you, as the client, agree to:
Provide Accurate Information
Provide accurate and comprehensive information, including site details, preferences, and project objectives.
Grant Access
Grant timely access to project sites for Bimitry’s team and any contractors or vendors involved.
Respond Promptly
Respond promptly to requests for approvals or additional information to prevent project delays.
Ensure Compliance
Ensure compliance with all local regulations, zoning requirements, and homeowner association rules.
Failure to meet these responsibilities may result in delays, additional costs, or adjustments to project timelines.
6. Fees and Payments
Fee Structure
All fees, including deposits, design costs, and project management charges, will be outlined in the project agreement. Clients are expected to review and agree to these terms before work begins.
Payment Schedules
Payment schedules will be detailed in the project agreement, typically including an initial deposit, milestone payments, and final settlement upon project completion.
Late Payments
Payments not received by the agreed-upon deadlines may incur late fees or interest charges. Persistent non-payment may result in suspension or termination of services.
Bimitry reserves the right to withhold deliverables or cease work if payments are overdue.
7. Confidentiality
We take confidentiality seriously. Bimitry commits to safeguarding all information you share with us, including personal details, project specifications, and proprietary ideas. Your information will only be shared with third parties directly involved in the project, such as contractors or consultants, and solely for project execution purposes.
Exceptions to this confidentiality include cases where disclosure is required by law or necessary to protect Bimitry’s legal or financial interests.
8. Limitation of Liability
Unforeseen Circumstances
Bimitry is not responsible for delays, cost overruns, or damages caused by unforeseen circumstances, including natural disasters, third-party errors, or changes in regulations.
Compliance Verification
Clients are responsible for verifying that completed designs comply with applicable building codes, as interpretations of codes may vary by jurisdiction.
Liability Limit
Under no circumstances shall Bimitry’s liability exceed the fees paid for the specific project in question.
9. Warranties and Disclaimers
Warranties
Bimitry warrants that services will be delivered in a professional, timely, and competent manner.
Disclaimers
We do not guarantee specific project outcomes, such as regulatory approvals, permits, or final construction costs. Our designs and recommendations are provided based on the best information available at the time.
Clients acknowledge that the ultimate responsibility for construction execution and adherence to local codes rests with contractors and builders.
10. Termination
Termination Notice
By providing written notice outlining reasons for termination.
Non-Compliance
If the client fails to meet payment obligations, Bimitry reserves the right to terminate services after providing notice of non-compliance.
Payment for Work Completed
Upon termination, clients are required to pay for all work completed up to the termination date, including any applicable termination fees.
Bimitry will cooperate to ensure a smooth transition upon termination, including transferring applicable project materials.
11. Governing Law
These Terms and Conditions are governed by the laws of [Jurisdiction]. In the event of a dispute, the parties agree to resolve matters through mediation or arbitration before pursuing litigation.
12. Changes to Terms
Bimitry reserves the right to amend these Terms and Conditions at any time. Updates will be posted on our website, and clients will be notified of significant changes. Continued use of our services constitutes acceptance of the revised terms.
Contact Us
If you have any questions about this Privacy Policy or our data practices, please reach out to us:
